核电工程总包合同协议书范本.docx

核电工程总包合同协议书范本总包合同协议书范本Contract Agreement for Nuclear Power Project一、签约方：甲方：（甲方全称）、法定代表人：（姓名）、地址：（详细地址）、电话：（联系电话）乙方：（乙方全称）、法定代表人：（姓名）、地址：（详细地址）、电话：（联系电话）鉴于甲方具有丰富的核电工程设计与建设经验，乙方具有出色的工程总包承包能力，双方本着互利共赢的原则，达成如下合作协议：第一条 项目背景1.1 甲方是一家具有核电工程设计与施工经验的公司，拥有一支经验丰富的工程设计与施工团队。1.2 乙方是一家具有承包核电工程总包项目能力的公司，拥有强大的施工队伍和管理团队。第二条 项目范围2.1 甲方委托乙方承包核电工程总包项目，包括但不限于设计、采购、施工、监理等全过程服务。2.2 乙方应按照相关法律法规和甲方要求，完成核电工程总包项目的各项工作，确保工程质量和工期的按时保质完成。第三条 服务内容3.1 乙方应当按照甲方提供的设计图纸和技术要求，进行全面的施工准备工作。3.2 乙方应当严格按照工程进度计划，合理安排施工工序，保障工程进度和质量。3.3 乙方应当配合甲方进行施工现场检查和质量验收工作，确保施工质量符合相关标准和要求。第四条 价格及支付方式4.1 核电工程总包项目的合同价款为（具体金额），包括设计、采购、施工、监理等全部费用。4.2 甲方应当根据工程进度及验收情况，按照约定的支付比例及时间节点，及时支付合同价款。第五条 合同变更5.1 在核电工程总包项目施工过程中，如有变更需求，需经双方协商一致后签订变更协议。5.2 变更协议应明确变更内容、费用调整及工期调整等事项，需经甲方和乙方双方签字确认后生效。第六条 保证和赔偿6.1 乙方保证按照约定的工程质量要求和标准进行施工，确保工程符合相关法规和标准。6.2 乙方应承担由于施工质量问题或工程延误导致的损失，按照约定的赔偿方式进行赔偿。第七条 合同解除7.1 如因不可抗力等原因导致合同无法继续履行，双方应友好协商解决，并尽快办理解除手续。7.2 合同解除后，双方应按照已完成工程量支付相应款项，并互不追究其他责任。第八条 争议解决8.1 若因履行本合同发生争议，双方应首先通过友好协商解决。8.2 若协商仍未达成一致意见，应提交至仲裁机构进行仲裁，仲裁裁决为终局裁决。第九条 其他9.1 本合同未尽事宜，由双方协商解决。9.2 本合同一式两份，自双方签字盖章后生效，具有同等法律效力。甲方（盖章）： 乙方（盖章）：签署日期：年 月 日Contract Agreement for Nuclear Power ProjectParty A: (Full name of Party A), Legal Representative: (Name), Address: (Detailed address), Phone: (Contact number)Party B: (Full name of Party B), Legal Representative: (Name), Address: (Detailed address), Phone: (Contact number)Whereas Party A has rich experience in nuclear power engineering design and construction, and Party B has excellent general contracting capabilities, both parties, in the spirit of mutual benefit and win-win cooperation, have reached the following cooperation agreement:Article 1 Background of the Project1.1 Party A is a company with experience in nuclear power engineering design and construction, and has an experienced engineering design and construction team.1.2 Party B is a company with the ability to contract for nuclear power engineering general contracting projects, and has a strong construction team and management team.Article 2 Scope of the Project2.1 Party A entrusts Party B to contract for the nuclear power engineering general contracting project, including but not limited to design, procurement, construction, supervision, and other full-process services.2.2 Party B shall, in accordance with relevant laws and regulations and the requirements of Party A, complete various tasks of the nuclear power engineering general contracting project to ensure the quality and timely completion of the project.Article 3 Service Content3.1 Party B shall carry out comprehensive construction preparation work according to the design drawings and technical requirements provided by Party A.3.2 Party B shall reasonably arrange construction procedures in accordance with the project schedule, ensuring the progress and quality of the project.3.3 Party B shall cooperate with Party A in conducting construction site inspections and quality acceptance work to ensure that the construction quality meets the relevant standards and requirements.Article 4 Price and Payment Method4.1 The contract price for the nuclear power engineering general contracting project is (specific amount), including all expenses for design, procurement, construction, supervision, etc.4.2 Party A shall timely pay the contract price according to the agreed payment proportion and time nodes based on the project progress and acceptance situation.Article 5 Contract Change5.1 During the construction process of the nuclear power engineering general contracting project, if there is a change requirement, a change agreement shall be signed after mutual agreement between both parties.5.2 The change agreement shall specify the changed content, fee adjustment, and schedule adjustment, and shall take effect after being signed and confirmed by both Party A and Party B.Article 6 Guarantee and Compensation6.1 Party B guarantees that the construction shall be carried out in accordance with the agreed quality requirements and standards to ensure that the project complies with relevant laws and regulations.6.2 Party B shall bear the losses caused by construction quality issues or project delays, compensating according to the agreed compensation method.Article 7 Contract Termination7.1 If the contract cannot be continued due to force majeure or other reasons, both parties shall resolve it amicably and complete the termination procedures as soon as possible.7.2 After the contract is terminated, both parties shall pay the corresponding amount based on the completed project quantity, and shall not hold each other liable for other responsibilities.Article 8 Dispute Resolution8.1 If a dispute arises in the performance of this contract, the parties shall first attempt to resolve it through amicable negotiation.8.2 If no consensus can be reached through negotiation, the dispute shall be submitted to an arbitration institution for arbitration, and the arbitration award shall be final and binding.Article 9 Miscellaneous9.1 Matters not covered in this contract shall be resolved through mutual consultation.9.2 This contract, in duplicate, shall come into effect upon signature and seal by both parties, with equal legal effect.Party A (Seal): Party B (Seal):Date of Signature: Year Month Day以上文本为核电工程总包合同协议书范本，甲乙双方需根据实际合作情况适当调整和完善合同条款，以确保合同的准确性和可执行性。希望双方能够遵守合同约定，共同推动核电工程总包项目的顺利实施和成功完成。