建设工程合同范本五篇.docx

建设工程合同范本五篇文章一：建设工程施工合同范本中文版：【合同编号】：XXX-XXXX-XXXX【甲方】（以下简称甲方）：_ 公司【乙方】（以下简称乙方）：_ 公司鉴于甲方需要进行建设工程，乙方具有相应的建设工程施工资质和经验，双方本着平等互利、诚实守信的原则，就建设工程施工事宜达成如下协议：第一条 项目名称和地点甲方委托乙方进行_项目的建设工程施工，项目地点位于_。第二条 合同价格本建设工程的合同价格为_元（大写：_元整），双方一次性支付。第三条 工程开工与完工时间1. 工程开工时间为合同签署后的_天内，具体日期双方商议确定。2. 工程完工时间为合同签署后的_天内，具体日期双方商议确定。第四条 工程质量要求1. 乙方承诺按照国家相关法律法规和建设工程质量标准，保证工程质量符合合同约定的标准。2. 工程施工过程中如发现任何质量问题，乙方应及时解决，确保工程质量。第五条 工程款支付方式1. 工程款分两次支付。工程开工前支付_%作为工程款，工程完工后支付剩余_%作为工程款。2. 工程款支付方式为_。第六条 合同变更1. 如有需要对合同提出变更，应由双方协商一致，并签订书面变更协议。2. 双方一致同意变更后，应及时办理相关手续并履行变更后的合同。第七条 违约责任1. 如一方未履行合同约定的义务，应承担相应的违约责任。2. 违约一方应赔偿对方因此造成的损失，赔偿方式为_。3. 如因不可抗力原因造成履约困难，应及时通知对方并协商解决方案。第八条 合同解除若因不可抗力等原因导致无法履行合同，双方可协商解除合同，已支付款项按实际履约部分计算。第九条 争议解决因合同履行产生的争议，双方应友好协商解决；协商不成的，提交_仲裁委员会仲裁。第十条 其他事项1. 本合同自双方签字盖章后生效，有效期为_年。2. 未尽事宜，双方可补充协商解决。甲方（盖章）：_ 公司 乙方（盖章）：_ 公司签订日期：_ 年 月 日英文版：【Contract No.】: XXX-XXXX-XXXX【Party A】(hereinafter referred to as Party A): Company Name【Party B】(hereinafter referred to as Party B): Company NameWhereas Party A needs to carry out construction projects and Party B has the corresponding construction qualifications and experience, both parties, in the principles of equality, mutual benefit, honesty and trustworthiness, have reached the following agreement on the construction project:Article 1 Project Name and LocationParty A entrusts Party B to carry out the construction of the _ project, located in _.Article 2 Contract PriceThe contract price for this construction project is _ RMB (in words: _ RMB), which shall be paid in full at once.Article 3 Commencement and Completion Time1. The commencement of the project shall be within _ days after the signing of the contract, with the specific date to be determined through negotiation.2. The completion of the project shall be within _ days after the signing of the contract, with the specific date to be determined through negotiation.Article 4 Quality Requirements1. Party B undertakes to ensure that the quality of the construction project meets the standards agreed upon in the contract in accordance with relevant national laws and regulations and construction quality standards.2. In case of any quality issues during the construction process, Party B shall promptly resolve them to ensure the quality of the project.Article 5 Payment Method for Project Funds1. The project funds shall be paid in two installments. _% of the project funds shall be paid before the commencement of the project, and the remaining _% shall be paid upon completion of the project.2. The payment method for the project funds is _.Article 6 Contract Changes1. If there is a need to make changes to the contract, both parties shall negotiate and agree on the changes, and sign a written agreement for the changes.2. Once both parties agree on the changes, they shall promptly complete the necessary procedures and fulfill the amended contract.Article 7 Breach of Contract Liability1. If either party fails to fulfill the obligations stipulated in the contract, they shall bear the corresponding liability for breach of contract.2. The defaulting party shall compensate the other party for any losses incurred, with compensation to be carried out in _ manner.3. In case of difficulties in performance due to force majeure, the party should promptly notify the other party and negotiate a solution.Article 8 Contract TerminationIf it becomes impossible to fulfill the contract due to force majeure or other reasons, both parties may negotiate the termination of the contract, and the amount already paid shall be calculated based on the actual performance.Article 9 Dispute ResolutionIn the event of disputes arising from the performance of the contract, both parties shall resolve them through amicable negotiation. If negotiation fails, the dispute shall be submitted to _ Arbitration Commission for arbitration.Article 10 Other Matters1. This contract shall come into effect upon the signing and sealing by both parties and shall be valid for _ years.2. Any matters not addressed in the contract may be supplemented and resolved through negotiation by both parties.Party A (Seal): Company Name Party B (Seal): Company NameDate of Signing: Year Month Day-文章二：建设工程勘察合同范本中文版：【合同编号】：XXX-XXXX-XXXX【甲方】（以下简称甲方）：_ 公司【乙方】（以下简称乙方）：_ 公司鉴于甲方需要进行建设工程勘察，乙方具有相应的勘察资质和经验，双方本着平等互利、诚实守信的原则，就建设工程勘察事宜达成如下协议：第一条 项目名称和地点甲方委托乙方进行_项目的勘察工作，项目地点位于_。第二条 服务内容1. 乙方应根据甲方需求，进行相关建设工程的勘察工作，确保勘察结果准确可靠。2. 勘察内容包括但不限于_。第三条 服务费用本建设工程的勘察服务费用为_元（大写：_元整），双方一次性支付。第四条 勘察工作时间1. 勘察工作应在合同签署后的_天内进行，具体日期双方商议确定。2. 如因不可抗力原因导致勘察工作延期，双方应协商解决。第五条 报告提交乙方应在完成勘察工作后，按照约定时间提交相关勘察报告给甲方，确保报告及时准确。第六条 保密条款双方约定严格遵守勘察结果的保密要求，未经甲方同意，不得将勘察结果泄露给第三方。第七条 违约责任1. 如一方未履行合同约定的义务，应承担相应的违约责任。2. 违约一方应赔偿对方因此造成的损失，赔偿方式为_。3. 如因不可抗力原因造成履约困难，应及时通知对方并协商解决方案。第八条 合同解除若因不可抗力等原因导致无法履行合同，双方可协商解除合同，已支付款项按实际履约部分计算。第九条 争议解决因合同履行产生的争议，双方应友好协商解决；协商不成的，提交_仲裁委员会仲裁。第十条 其他事项1. 本合同自双方签字盖章后生效，有效期为_年。2. 未尽事宜，双方可补充协商解决。甲方（盖章）：_ 公司 乙方（盖章）：_ 公司签订日期：_ 年 月 日英文版：【Contract No.】: XXX-XXXX-XXXX【Party A】(hereinafter referred to as Party A): Company Name【Party B】(hereinafter referred to as Party B): Company NameWhereas Party A needs to conduct construction project investigation, and Party B has the corresponding qualifications and experience in investigation, both parties, in the principles of equality, mutual benefit, honesty and trustworthiness, have reached the following agreement on the construction project investigation:Article 1 Project Name and LocationParty A entrusts Party B to conduct investigation work for the _ project, located in _.Article 2 Service Content1. Party B shall perform investigation work for the relevant construction projects according to the needs of Party A, ensuring the accuracy and reliability of the investigation results.2. The investigation content includes but is not limited to _.Article 3 Service FeesThe service fee for this construction project investigation is _ RMB (in words: _ RMB), which shall be paid in full at once.Article 4 Investigation Work Time1. The investigation work shall be carried out within _ days after the signing of the contract, with the specific date to be determined through negotiation.2. If the investigation work is delayed due to force majeure, both parties shall negotiate to resolve the delay.Article 5 Report SubmissionAfter completing the investigation work, Party B shall submit the relevant investigation report to Party A according to the agreed upon time, ensuring the report is timely and accurate.Article 6 Confidentiality ClauseBoth parties agree to strictly abide by the confidentiality requirements of the investigation results and shall not disclose the investigation results to third parties without the consent of Party A.Article 7 Breach of Contract Liability1. If either party fails to fulfill the obligations stipulated in the contract, they shall bear the corresponding liability for breach of contract.2. The defaulting party shall compensate the other party for any losses incurred, with compensation to be carried out in _ manner.3. In case of difficulties in performance due to force majeure, the party should promptly notify the other party and negotiate a solution.Article 8 Contract TerminationIf it becomes impossible to fulfill the contract due to force majeure or other reasons, both parties may negotiate the termination of the contract, and the amount already paid shall be calculated based on the actual performance.Article 9 Dispute ResolutionIn the event of disputes arising from the performance of the contract, both parties shall resolve them through amicable negotiation. If negotiation fails, the dispute shall be submitted to _ Arbitration Commission for arbitration.Article 10 Other Matters1. This contract shall come into effect upon the signing and sealing by both parties and shall be valid for _ years.2. Any matters not addressed in the contract may be supplemented and resolved through negotiation by both parties.Party A (Seal): Company Name Party B (Seal): Company NameDate of Signing: Year Month Day-文章三：建设工程设计合同范本中文版：【合同编号】：XXX-XXXX-XXXX【甲方】（以下简称甲方）：_ 公司【乙方】（以下简称乙方）：_ 公司鉴于甲方需要进行建设工程设计，乙方具有相应的设计资质和经验，双方本着平等互利、诚实守信的原则，就建设工程设计事宜达成如下协议：第一条 项目名称和地点甲方委托乙方进行_项目的设计工作，项目地点位于_。第二条 服务内容1. 乙方应根据甲方需求，进行相关建设工程的设计工作，确保设计方案科学合理。2. 设计内容包括但不限于_。第三条 服务费用本建设工程的设计服务费用为_元（大写：_元整），双方一次性支付。第四条 设计工作时间1. 设计工作应在合同签署后的_天内进行，具体日期双方商议确定。2. 如因不可抗力原因导致设计工作延期，双方应协商解决。第五条 设计文件提交乙方应在完成设计工作后，按照约定时间提交相关设计文件给甲方，确保文件符合设计要求。第六条 知识产权乙方设计的所有文件、资料和成果等均属于乙方拥有的知识产权，未经乙方同意，不得擅自使用或向他人披露。第七条 违约责任1. 如一方未履行合同约定的义务，应承担相应的违约责任。2. 违约一方应赔偿对方因此造成的损失，赔偿方式为_。3. 如因