建设工程合同协议书范本八篇.docx

建设工程合同协议书范本八篇第一篇：建设工程总承包合同协议书范本中文版：甲方：_（委托人）乙方：_（承包人）鉴于甲方欲对建设工程进行承包，乙方有能力完成该建设工程，双方经友好协商，达成以下协议：第一条 项目名称本合同的项目名称为：_（工程名称）。第二条 项目地点本工程位置在_（具体地址）。第三条 合同价款1. 本合同的合同价款为人民币_元整（大写：_元整），包括工程款及税金等费用。2. 合同价款支付方式：分期支付，具体支付比例及时间见附件1付款计划。第四条 工程内容本建设工程包括但不限于_（具体工程内容），详细工程范围及要求见附件2工程说明书。第五条 工程工期1. 本工程的竣工日期为_年_月_日。2. 工程分期完成时间及节点见附件3工程进度计划。第六条 质量标准1. 工程质量应符合国家相关标准和甲方要求。2. 工程验收标准详见附件4工程验收标准。第七条 竣工验收1. 工程竣工后，乙方应邀请甲方对工程进行验收，确认工程质量合格后，方可办理竣工手续。2. 如发生质量问题，乙方应在合理时间内进行整改并重新邀请甲方验收。第八条 违约责任1. 若一方未履行本合同规定的义务，应承担违约责任。2. 违约责任详见附件5违约责任条款。第九条 税费1. 合同价款中的税费由双方按照国家相关规定分担。2. 若因政策变化引起的税费变化，由双方协商解决。第十条 争议解决本合同争议应友好协商解决，如协商不成，提交有管辖权的仲裁机构裁决。第十一条 其他事项1. 本合同自双方盖章生效，附件具有本合同同等法律效力。2. 未尽事宜，双方可另行协商解决。甲方（盖章）：_ 乙方（盖章）：_日期：年 月 日英文版：Party A: _ (Client)Party B: _ (Contractor)Whereas Party A intends to contract for the construction project and Party B has the capability to complete the said construction project. After friendly negotiations, the parties hereto have entered into the following agreement:Article 1 Project NameThe project name of this contract is: _ (Project Name).Article 2 Project LocationThe project is located at _ (Specific Address).Article 3 Contract Price1. The contract price of this contract is RMB _ Yuan (in words: _ Yuan), including construction costs and taxes.2. Payment terms of the contract price: payment in installments, specific payment ratios and times are detailed in Appendix 1 Payment Schedule.Article 4 Project ScopeThe construction project includes but is not limited to _ (Specific Project Scope), detailed project scope and requirements can be found in Appendix 2 Project Specifications.Article 5 Project Duration1. The completion date of the project is _ (Year/Month/Day).2. The completion time and milestones of the project can be found in Appendix 3 Project Schedule.Article 6 Quality Standards1. The quality of the project shall comply with national standards and the requirements of Party A.2. Detailed acceptance criteria for the project can be found in Appendix 4 Acceptance Standards.Article 7 Completion Acceptance1. After the project is completed, Party B shall invite Party A to inspect the project. Upon confirmation of the qualified quality of the project, completion procedures can be carried out.2. In case of quality issues, Party B shall rectify them within a reasonable time and invite Party A for re-inspection.Article 8 Breach of Contract Liability1. If either party fails to perform its obligations under this contract, it shall bear liability for breach of contract.2. Details of breach of contract liability can be found in Appendix 5 Breach of Contract Clause.Article 9 Taxes and Fees1. Taxes and fees in the contract price shall be shared by both parties in accordance with relevant national regulations.2. If changes in taxes and fees occur due to policy changes, they shall be resolved through negotiation between the parties.Article 10 Dispute ResolutionAny disputes arising from this contract shall be resolved through friendly negotiation. If negotiation fails, they shall be submitted to an arbitration institution with jurisdiction for resolution.Article 11 Other Matters1. This contract shall come into effect upon signature and seal by both parties, and the appendices shall have the same legal effect as this contract.2. Matters not covered herein shall be resolved by mutual agreement between the parties.Party A (Seal): _ Party B (Seal): _Date: Year Month Day-第二篇：建设工程施工合同协议书范本中文版：甲方：_（委托人）乙方：_（施工方）鉴于甲方拟对建设工程进行施工，乙方具有相应资质和经验，双方经协商一致，达成如下协议：第一条 项目名称本合同项目名称为：_（工程名称）。第二条 项目地点本工程位置在_（具体地址）。第三条 价格和支付方式1. 本合同总价款为人民币_元整（大写：_元整），具体支付方式按照工程进度分期支付，详见附件1付款计划。2. 工程确需变更，费用变化应重新协商确定。第四条 工程内容本工程包括但不限于_（具体工程内容），详细工程范围和要求见附件2工程说明书。第五条 工期和竣工验收1. 工程须于_年_月_日竣工交付使用，详细工期见附件3工程进度计划。2. 工程竣工后，乙方应通知甲方进行验收，确认合格后，完成竣工手续。第六条 质量和保修1. 工程质量应符合国家标准及合同要求。2. 乙方应负责提供工程保修期为_年的服务，详细保修条款见附件4保修协议。第七条 合同变更1. 如工程需要进行变更，应协商一致确定变更内容及费用。2. 双方在变更记录表上签字确认后，变更内容生效。第八条 争议解决在履行合同过程中如发生争议，双方应先行协商解决，协商不成的，应提交有管辖权的仲裁机构解决。第九条 其他事项1. 附件和补充本合同，具有同等的法律效力。2. 本合同未尽事宜，双方可另行协商解决。甲方（盖章）：_ 乙方（盖章）：_日期：年 月 日英文版：Party A: _ (Client)Party B: _ (Construction Company)Whereas Party A intends to carry out construction works for a construction project and Party B has the corresponding qualifications and experience. After negotiations, the parties have agreed to the following terms:Article 1 Project NameThe project name of this contract is: _ (Project Name).Article 2 Project LocationThe project is located at _ (Specific Address).Article 3 Price and Payment Terms1. The total contract price of this contract is RMB _ Yuan (in words: _ Yuan), with payment to be made in installments according to the progress of the project. Detailed payment terms can be found in Appendix 1 Payment Schedule.2. If changes to the project are necessary, the cost adjustments shall be renegotiated and agreed upon.Article 4 Project ScopeThe construction project includes but is not limited to _ (Specific Project Scope), detailed project scope and requirements can be found in Appendix 2 Project Specifications.Article 5 Project Duration and Acceptance1. The project must be completed and delivered for use by _ (Year/Month/Day), detailed project duration can be found in Appendix 3 Project Schedule.2. After completion of the project, Party B shall notify Party A for acceptance. Upon confirmation of qualification, completion procedures shall be finalized.Article 6 Quality and Warranty1. The quality of the project shall comply with national standards and contract requirements.2. Party B shall be responsible for providing a service warranty period of _ years for the project, with detailed warranty terms in Appendix 4 Warranty Agreement.Article 7 Contract Changes1. If changes to the project are necessary, both parties shall agree on the change in content and cost.2. After both parties sign and confirm the change record, the change shall come into effect.Article 8 Dispute ResolutionIn case of disputes during the contract performance, the parties shall first negotiate for resolution. If negotiation fails, the disputes shall be submitted to an arbitration institution with jurisdiction for resolution.Article 9 Other Matters1. Appendices and additional agreements have the same legal effect as this contract.2. Matters not covered in this contract shall be resolved through further negotiation between the parties.Party A (Seal): _ Party B (Seal): _Date: Year Month Day-第三篇：建设工程监理合同协议书范本中文版：甲方：_（监理单位）乙方：_（监理工程师）鉴于甲方拟委托乙方对建设工程进行监理，双方就下列事项达成如下协议：第一条 项目名称本合同监理的项目名称为：_（工程名称）。第二条 项目地点本工程位置在_（具体地址）。第三条 服务内容1. 乙方应对整个工程进度、质量、安全等进行监督和检查，确保工程按计划进行。2. 乙方应提出工程的实施方案，报甲方审核。第四条 报酬1. 本合同的监理费用为人民币_元整（大写：_元整），支付方式按照实际工作量结算，详见附件1报酬计划。2. 如监理工作超出预算，须经双方协商确定后支付。第五条 工程验收1. 工程竣工后，乙方应协助甲方对工程进行验收，确保工程质量符合国家标准和合同要求。2. 如验收过程中发现问题，乙方应协助整改并重新验收。第六条 保密义务乙方应对甲方的商业秘密和机密信息承担保密义务，不得泄露给第三方。第七条 违约责任若一方未履行本合同规定的义务，应负相应的违约责任，详细责任由双方另订具体书面补充协议解决。第八条 争议解决如双方在本合同履行中发生争议，应立即协商解决，协商不成的，提交有管辖权的仲裁机构裁决。第九条 其他事项1. 本合同自双方签字盖章后生效，附件具有同等法律效力。2. 未尽事宜，双方可以协商补充或变更。甲方（盖章）：_ 乙方（盖章）：_日期：年 月 日英文版：Party A: _ (Supervision Unit)Party B: _ (Supervision Engineer)Whereas Party A intends to entrust Party B to supervise the construction project, the parties have reached the following agreement:Article 1 Project NameThe project to be supervised under this contract is: _ (Project Name).Article 2 Project LocationThe project is located at _ (Specific Address).Article 3 Service Scope1. Party B shall supervise and inspect the progress, quality, safety, and other aspects of the entire project to ensure that the project proceeds as planned.2. Party B shall propose the implementation plan for the project and submit it for approval by Party A.Article 4 Compensation1. The supervision fee under this contract is RMB _ Yuan (in words: _ Yuan), to be settled based on actual work volume. Detailed payment terms can be found in Appendix 1 Compensation Plan.2. If the supervision work exceeds the budget, it must be agreed upon by both parties before payment.Article 5 Project Acceptance1. After the completion of the project, Party B shall assist Party A in conducting the project acceptance to ensure that the quality of the project meets national standards and contract requirements.2. If any issues are discovered during acceptance, Party B shall assist in rectification and re-inspection.Article 6 Confidentiality ObligationsParty B shall be responsible for maintaining the confidentiality of Party As business secrets and confidential information, and shall not disclose them to third parties.Article 7 Breach of Contract LiabilityIf either party fails to fulfill its obligations under this contract, it shall bear corresponding liability for breach of contract. Detailed responsibilities shall be resolved through a specific written supplemental agreement by both parties.Article 8 Dispute ResolutionIn case of disputes between the parties during the performance of this contract, they shall immediately negotiate for resolution. If negotiation fails, the disputes shall be submitted