路桥建设工程合同协议书范本.docx

路桥建设工程合同协议书范本正文：合同协议书一、甲方：_公司地址：_电话：_传真：_联系人：_乙方：_公司地址：_电话：_传真：_联系人：_为了确保本合同双方的权益，维护双方的合法权益，根据中华人民共和国合同法及相关法律法规的规定，经双方协商，就_工程项目（以下简称“本工程”）的路桥建设合同达成如下协议：第一条 工程项目地址：_第二条 项目概况：1. 工程项目的建设内容、规模、技术要求、质量标准、工程造价以及竣工验收的方式等相关内容详见附件工程合同技术条款。2. 乙方应按照甲方提供的施工图纸和相关技术要求进行施工。3. 工程建设单位为_公司。第三条 工程合同价款和支付方式：1. 工程合同总价款为_元人民币。2. 工程款支付方式：甲方应按照工程进度，将合同价款分期支付给乙方。具体支付比例和时间详见附件工程合同价款支付进度表。第四条 工程工期：1. 工程合同工期为_天。2. 工程施工起止日期：_至_。第五条 竣工验收：1. 工程验收标准：乙方应按照施工规范和建筑工程质量验收规范的相关要求进行施工，确保工程质量达到验收标准。2. 工程竣工验收程序：甲方组织验收人员对工程项目进行竣工验收，验收合格后方可进行结算支付。第六条 违约责任：1. 若因乙方原因导致工程项目无法按期交付或者工程质量不达标的，乙方应承担相应的违约责任。2. 若因甲方原因导致工程款无法按时支付或者超过约定支付期限的，甲方应承担相应的违约责任。第七条 保密条款：双方应对接触到的商业秘密和合同履行过程中获知的技术、商业、财务等信息负有保密义务，不得泄露给第三方。第八条 其他事项：1. 外加工：乙方在承揽本合同工程时，严禁将工程分包或者外包给其他单位或个人进行加工。2. 材料质量：乙方在工程建设过程中，应严格按照相关要求选择优质材料，并经甲方同意后方可使用。3. 意外事件：在工程建设过程中出现的意外事件，双方应及时沟通协商解决，维护双方的合法权益。第九条 合同变更：若由于不可抗力等原因，需要对合同进行变更的，应经双方书面协商达成一致意见后方可变更。第十条 法律适用和争议解决：本合同适用中华人民共和国法律，并由双方友好协商解决。若协商不成的，应提交_仲裁委员会仲裁。第十一条 合同生效：本合同两份，双方各执一份，经双方盖章后生效。本合同自签订之日起生效。甲方（盖章）：_日期：_乙方（盖章）：_日期：_Contract AgreementParty A: _ CompanyAddress: _Phone: _Fax: _Contact Person: _Party B: _ CompanyAddress: _Phone: _Fax: _Contact Person: _In order to ensure the rights and interests of both parties and safeguard their legitimate rights and interests, in accordance with the Contract Law of the Peoples Republic of China and relevant laws and regulations, and after consultation between the two parties, the following agreement is reached on the contract for the construction of roads and bridges for the _ project (hereinafter referred to as this project):Article 1 Project Address: _Article 2 Project Overview:1. The construction content, scale, technical requirements, quality standards, construction cost, and completion acceptance methods of the project are detailed in the attached Technical Terms of the Engineering Contract.2. Party B shall carry out the construction in accordance with the construction drawings and related technical requirements provided by Party A.3. The construction unit of the project is _ Company.Article 3 Contract Price and Payment Method:1. The total contract price of the project is _ RMB.2. Payment method of the contract price: Party A shall make stage payments to Party B according to the progress of the project. The specific payment ratio and schedule are detailed in the attached Engineering Contract Price Payment Schedule.Article 4 Project Duration:1. The contract period of the project is _ days.2. Project construction start and end date: From _ to _.Article 5 Completion Acceptance:1. Acceptance standards of the project: Party B shall carry out the construction in accordance with the relevant requirements of the Construction Specifications and Regulations for Quality Acceptance of Construction Projects to ensure that the quality of the project meets the acceptance standards.2. Completion acceptance procedure: Party A shall organize inspectors to conduct completion acceptance of the project. Payment settlement can only be made after the acceptance is qualified.Article 6 Default Liability:1. If the project cannot be delivered on time or the quality does not meet the standards due to Party Bs reasons, Party B shall bear the corresponding liability for breach of contract.2. If the project payment cannot be made on time or exceeds the agreed payment deadline due to Party As reasons, Party A shall bear the corresponding liability for breach of contract.Article 7 Confidentiality:Both parties shall be obliged to maintain confidentiality of any commercial secrets and technical, business, and financial information acquired during the contract performance, and shall not disclose it to any third party.Article 8 Other Matters:1. External Processing: Party B is strictly prohibited from subcontracting or outsourcing the project to other units or individuals for processing.2. Material Quality: Party B should select quality materials in strict accordance with the relevant requirements during the project construction, and may only use them with the consent of Party A.3. Accidents: In case of accidents during the project construction, both parties shall promptly communicate and negotiate to resolve them and protect their legitimate rights and interests.Article 9 Contract Change:If it is necessary to change the contract due to force majeure or other reasons, it shall be changed with the written consent of both parties.Article 10 Applicable Law and Dispute Resolution:This contract shall be governed by the laws of the Peoples Republic of China and shall be resolved by friendly consultation between the parties. If no agreement can be reached, it shall be submitted to _ Arbitration Commission for arbitration.Article 11 Contract Effectiveness:This contract is in duplicate, with each party holding one copy, and shall come into effect upon being stamped and signed by both parties. This contract shall take effect from the date of signing.Party A (Seal): _Date: _Party B (Seal): _Date: _ (Note: This is a sample contract agreement for road and bridge construction project. It covers essential aspects such as project details, contract price, payment terms, completion acceptance, default liabilities, confidentiality, and dispute resolution. Parties involved should carefully review and customize the agreement to suit the specific requirements of their project.)