景观工程设计合同中英文.doc

景观工程设计协议中英文Design Contract of Landscape Design 项目名称：Project Name: 景观设计 Landscape Design项目地点： Project Location:委托方（甲方）：Clients (Party A):承接方（乙方）：Contractor (Party B)：签订日期：Date: 年 月 日 第一章 本协议根据列文献签订Chapter1. The Contract in according to following documents:1.1国家及地方有关建设工程勘察设计管理法规和规章。 National and local administrative Law and regulations of construction project design1.2建设工程同意文献。 The approval document of construction project1.3省市有关规定和本工程实际状况。 Provincial and municipal regulations and the actual situation of the project.第二章 设计征询范围及内容 Scope of design consultation and content乙方设计征询范围 Scope of design consultation for Party B本次设计景观总面积约为 平方米。甲方同意委托乙方承担其景观设计征询工作。The total area of the landscape design is square meters. Party A agrees to entrust Party B for the consultative and design work.本协议包括工作阶段： 景观方案设计、扩初设计、施工图设计。The work stage of this contract include: project design of landscape, preliminary design, construction drawing design第三章 甲方需向乙方提交有关资料、文献及时间 The related data, document and time that Party A should submit to Party B甲方在规定时间内向乙方提交基础资料及文献，并对其完整性、对性、及时性负责。Party A shall submit the basic data and document on time, and responsible for its integrity, correct and timeliness3.1 甲方应于方案设计开始前提交有关资料The related data that Party A shall submit before the design3.1.1设计任务委托书 Letter of authorization 3.1.2规划总图（彩色平面图、1/500报批图） General layout of planning (color floor plan, 1/500 drawing)3.1.3建筑立面效果图 Architectural effect drawing 3.1.4规划设计阐明 Illustrations of design layout3.1.5项目筹划方案 Scheme for project3.1.6建筑首层平面 The first floor layout of the building3.1.7基地竖向条件图 Vertical design drawing of the building3.2甲方应于初步设计开始前提交有关资料The related data that Party A shall submit before the tentative design3.2.1方案设计确认书 Scheme design confirmation letter3.2.2建筑首层平面 The first floor layout of the building3.2.3建筑立面剖面施工图 Architectural facade profile construction drawing3.2.4竖向设计图 Vertical design drawing3.2.5地下建筑平面竖向施工图 Underground floor vertical construction drawing3.2.6综合管网施工图 Comprehensive pipe network construction drawing3.3甲方应于施工图设计开始前提交有关资料 The related data that Party A shall submit before design3.3.1初步设计确认书 Preliminary design confirmation letter3.3.2水源控制方式、位置来源 Water sources control method, source location3.3.3电源控制位置、电源控制间位置 Power control location, power control room location3.3.4地质勘测汇报 Geological prospecting report第四章 本协议设计项目工作阶段及成果 The contract design work phase of the project and results4.1第一阶段：方案设计 First phase：Scheme design4.1.1工作成果： Work Resultsa方案设计阐明； Scheme design instructionb景观方案总平面图； Floor plan of the overall landscape schemec分析图（包括景辨别布、功能布置、空间及场所分析、交通分析）； Analysis (includes scenic layout, space distribution, function and place analysis, traffic analysis)；d重要区域景观方案放大设计图； Enlarge chart of the main regional landscape plan designede重要景点效果图； Impression drawing of major attractions；f园林小品示意图； Gardens sketch diagramg景观设计示意图； Landscape design diagramh其他彩色图片； Other color picturesI提交A3图册六份； Deliver six atlas of A3 sizej汇报方式为草案汇报和电脑汇报。 Report method shall be draft report and computer report4.1.2此阶段用时 工作日； This stage takes workdays4.2第二阶段：扩初设计 The second phase: Preliminary design4.2.1 按甲方同意方案进行扩初设计。Designed according to Party A agreed scheme for preliminary design.4.2.2此阶段设计成果有 This stage of design work result includea景观初设总平面图； Preliminary landscape set general layoutb局部放大平面图、剖面图； Local enlargement of the plan, section plan；c园林小品平、立、剖面图； Gardens sketch layout, elevation and section pland种植图(重要树种及载植方式)； The planting layout (Main tree species and cultivated methods)e竖向图； Vertical plan；f局部景观立面图及剖面图； Partial landscape elevations and section plang灯具及栏杆式样； Lamps and railing styleh提交A3图册三份。 Deliver three atlas of A3 size4.2.3此阶段用时 工作日。 This stage takes workdays4.3第三阶段：施工图设计 The third phase ： Construction drawing design4.3.1 在扩初设计经甲方承认后，乙方将进行施工图设计工作。 After the design of preliminary design approved by Party A, Party B will start the construction drawing design.4.3.2 此阶段设计成果有： This stage of design work result include：a总平面图；. General layoutb局部放大平面图； Local enlargement of the floor plan；c放线图； Line figured种植图；. Plant figuree铺装图； Install figuref竖向图； Vertical plan；g 环境配电图； Surrounding power distribution chart ；h 环境给、排水图； Surrounding water supply and drainagei设计阐明、多种详图、植物名目； Design instruction, the detailed map, plants listj提供8套施工图纸。 Deliver eight sets design drawing4.3.3此阶段用时 工作日。 This stage takes workdays4.4现场服务阶段 The site service stage4.4.1在项目进入施工阶段后，乙方提供现场服务。 After commencing the construction phase of the project, Party B provide on-site service.4.4.2此阶段成果有： This stage of design work result include：a与施工方现场交底； communicate with construction contractor for the design intention.b现场效果控制； Jobsite construction controlc材料封样； Sealed sample materialsd 植物主材选定。 Plants selected4.4.3 此阶段用时 工作日。 This stage takes workdays第五章 设计费及支付方式 Design fee and the payment method5.1 本协议项目设计费，总额为人民币 ，小写 元整。（按景观面积 平方米，单价 元/平方米），The total project design fee of this contract is, RMB, ￥ . ( square meters of total landscape area, price: /square meter)5.2 乙方基本服务费用根据不一样阶段分列如下： Party B basic service fees according to the different stages are as follows:5.2.1 方案设计阶段：提交成果后 个工作日内，委托方应支付设计费人民币： 元整，小写 元（协议金额 %）。：Preliminary design phase: the client shall pay RMB of design fee, ￥ : ( % of contract total amount) within business day after submitting the results:5.2.2 方案扩初阶段：提交成果后 个工作日内，委托方支付设计费人民币 元整，小写 元（协议金额 %）。：Scheme design phase: the client shall pay RMB of design fee, ￥ : ( % of contract total amount) within business day after submitting the results:5.2.3 施工图阶段：提交成果后 个工作日内，委托方支付设计费人民币 元整，小写 元（协议金额 %）。：Construction drawing phase: the client shall pay RMB of design fee, ￥ : ( % of contract total amount) within business day after submitting the results:5.2.4 施工期间现场配合阶段：景观工程竣工验收后 个工作日，委托方支付费用为人民币 元整，小写 元（协议金额 %）。Jobsite cooperating phase: the client shall pay RMB of design fee, ￥ : ( % of contract total amount) within business day after the landscape construction completed and pass the acceptance examine: 5.3 其他：Others 甲方需委派一位人员，就此工程设计方向事宜上，负责批复乙方设计。如甲方规定乙方对已同意设计提供重大修改，或进行协议之外设计工作，应被视为额外服务项目，收费应由甲乙双方共同协定。Party A shall appoint a staff to in charge of Party Bs engineering design approval. If Party A request Party B to be make major adjustment on the design approved by Party A, or work on the design out of this contract scope, should be considered an additional service, fees should be design by mutual agreement of both parties.第六章 双方责任Chapter6 Responsibilities of parties6.1 甲方责任 Responsibilities of Party A6.1.1 甲方按本协议协定提交内容，在协定时间内向乙方提交资料及文献，并对其完整性、对性及时限负责。此外，甲方还应提供有关场地条件数据，包括公用事业、地理条件、道路使用权、限制条件等。 Party A shall submit the data and documents content in according to this contract stipulated, in agreed time limit, and be responsible for its integrity, correctness and time limit. In addition, Party A shall also provide the data about the conditions at the jobsite, including utilities, geographical conditions, road use right, constraints, etc.6.1.2 甲方提交上述资料及文献超过规定期限15天以内，乙方按协议规定交付设计文献时间顺延；期限超过15天以上时，乙方有权重新确定提交设计文献时间。 Party A delay to submitted the data and documents referred above in excess of the prescribed period within 15 days, Party B postpone deliver the design documents in according to the contract stipulation time. If the delay time more than 15 days, Party B has the right to determine a new submitted time for the design documents6.1.3 甲方变更委托设计项目、规模、条件或因提交资料错误，或所提资料作较大修改，以致导致乙方设计需返工时，双方除需另行协商签订补充协议（或另订协议）、重新明确有关条款外，甲方应按乙方所耗工作量向乙方支付返工费。 Party B design reworked causes by Party A change design projects, scale, conditions or because of the presented material mistakes, or mentioned material major revision. Both parties shall sign a supplementary agreement (or sign a new agreement) and redefine relevant terms, Party A shall pay associated rework fee to Party B in according to the workload.6.1.4 在协议履行期间，甲方规定终止或解除协议，乙方未开始设计工作，不退还甲方已付定金；已开始设计工作，甲方根据乙方已进行实际工作量，另行议定。 During the implement of the contract, Party A request to terminate or rescind the contract, Party B has not started design work, does not return prepaid deposit to Party a; design work has begun, Party A can negotiate with Party B for the fee in according to the actual workload.6.1.5 甲方应按本协议第五章规定金额和时间向乙方支付设计费用，每逾期一天，需承担应支付金额千分之二逾期违约金。逾期超过十四天以上时，乙方有权暂停履行下阶段工作，并书面告知甲方。 Party pay the design fee in according to the clause fifth of this contract, Late payment shall pay 0.2 % of the late payment amount penalty per day, if the late payment is overdue more than 14 days, Party B has the right to suspend its work for next stage, and notice in writing to Party A.6.1.6 甲方规定乙方比协议规定期间提前提交设计文献时，甲方应支付赶工费。 Party A requests Party B to submit the design documents before contract stipulated time, Party A shall pay the rush cost. 6.1.7 甲方应为乙方派驻现场工作人员提供工作、生活交通等方面便利条件，但费用由乙方自行承担。Party A should provide Party Bs on-site staffs work, living and traffic conveniences, but the cost shall be bear by Party B. 6.1.8 甲方应保护乙方设计版权，未经乙方同意，甲方对乙方交付设计文献不得向第三方转让，否则，乙方有权索赔。Party A shall protect Party Bs design copyright, Party A should not transfer the design documents to third party without the agreement of Party B, or else, Party B has the right to claim for compensation. 6.1.9 甲方有权在本项目对外宣传时使用乙方标识。 Party A has the right to use the logo of Party B in advertising the project.6.2 乙方责任 乙方按本协议协定提交内容、份数、在协定时间内向甲方提交成果，并对其完整性、对性、及时性负责。2.1 Party b shall submit the result content, number of copies stipulated in the agreement in time, and be responsibility of its completeness, correctness and timeliness. 6.2.2 乙方对设计文献出现遗漏、错误或甲方不满意之处负责修改或补充。由于乙方设计错误导致工程质量事故损失，乙方除负责采用补救措施外，应免收受损失部分 设计费，并根据损失程度向甲方偿付赔偿金。经甲方或上级主管部门审查后，在原定任务书设计范围内必要修改，乙方负责承担。 Party B shall modify or resupply the design document if there appeared omissions, false or unsatisfied by Party A. Due to the engineering quality accidents loss caused by Party Bs design error, party B shall reduce the relevant part design fee, in addition to take remedial measures and be liability for compensation according to the loss to Party As damages. After examination by Party A or superior departments in charge, amendments request within the scope the original specification design, Party B shall be liable. 6.2.3 由于乙方自身原因，延误了设计文献交付时间，每延误一天，应减收该项目设计费千分之二。Due to reason of Party B, if delivery time being delayed, Party B should reduce the project design fee of 2/1000 per delayed days. 6.2.4 乙方交付设计文献后，参与有关上级审查及根据审查结论负责不超过原定计划任务书范围内必要调整补充。不再计取费用。 After delivering design documents, Party B shall participate in relevant superior examination, and according to the review conclusion to add necessary adjustment. Supplement within the scope of original plan task, shall not charge for any additional fee.6.2.5 乙方不得向第三方扩散、转让甲方提交产品图纸等技术经济资料。如发生以上状况，甲方有权索赔。Party B shall not spread or transfer product drawings, other technical and economic data submitted by Party A to third party. If above circumstance happened, Party A has the right to claim for compensation. 6.2.6 乙方同意配合甲方按工程进度规定调整出图次序，付款方式可另行协商。Party B agrees to coordinate Party A to adjust drawing deliver order according to the schedule require, payment method can be separately negotiate by both parties.6.2.7 乙方必须根据设计原则、技术规范、设计任务阐明等有关景观设计原则进行设计，提交符合质量设计文献。Party B must submit the quality design documents in accordance with design standards, technical specifications and design task of relevant landscape design standards.6.2.8 乙方必须在满足方案原则前提下，选料用材时要注意到景观效果和造价关系，作到既满足景观效果规定，又最大程度减少造价。Party B shall choose materials quality in accordance with landscape effect and price under the standards of scheme, in satisfies the requirements effect and maximum reduce cost.第七章 补充条款 Supplemental condition 7.1 协议终止 Termination of contract7.1.1 甲方因自身原因不能履行本协议，应按照协议付清已完毕阶段设计任务对应设计费, 并承担协议总额10%给乙方作为违约金，协议终止。Party A unable to perform the contract due to its own reason, should pay the design fee of completed phase in accordance with the contract, and bear the 10% of the total contract amount as liquidated penalty, terminate the contract.7.1.2 乙方因自身原因无法履行协议，应退回所有设计费用，并承担协议总额10%给甲方作为违约金，协议终止。Party B unable to perform the contract due to its own reason, should pay 10% of the total contract amount as liquidated penalty, and terminate the contract.7 .1.3 由于不可抗力原因致使协议无法履行时，双方应及时协商处理。When unable to fulfill the contract due to force majeure factors, both parties should be resolved through consultation in a timely manner.7.2 未尽事宜及争议处理 Unmentioned matters and dispute result7.2.1 本协议未尽事宜，双方可签订补充协议作为附件，补充协议与本协议具有同等法律效力。Matters not concerned of this contract, both parties can signed a supplementary agreement as attachments, supplementary agreements and this contract have the same legal effect.7.2.2 在履行协议过程中，双方发生争议，应本着友好原则协商处理,协商不成，依法提交 仲裁委员会仲裁。During the implement of this contract, if dispute occur, should be resolved in negotiation with the principles of friendly consultation. Failed in negotiation, both party can submit it to Arbitration Commission for arbitration according to law.7.2.3 本协议合用于中华人民共和国法律。This contract apply to law of People Republic of China7.3 其他 others7.3.1 乙方为本协议项目服务到施工安装结束为止。Service provide by Party b to this contract shall be valid until the construction installation is complete.7.3.2 甲方委托乙方承担本协议内容以外工作服务，另行签订协议并支付费用。Other works entrusted by Party A to Party B beyond the range of this contract, shall entered into separate agreements and pay separate costs.7.3.3 本协议有效期自双方签字盖章之日起2年内有效。The contract is valid after both parties signed and sealed, the validation period is 2 years.7.3.4 本协议正本一式两份，双方各执一份，具有同等法律效力。 This original contract in duplicate, each party keeps one copy and has same legal effect.委托方：（盖章）Client (seal) 承接方（盖章）Contractor(seal) 签订协议代表（签字）： 签订协议代表（签字）：Representatives (signature): Representatives (signature):