园区开发合同协议书范本六篇.docx

园区开发合同协议书范本六篇
**园区开发合同协议书范本**
**1. 合作协议书**
中文：
甲方（开发公司名称）：
地址：
电话：
乙方（合作方名称）：
地址：
电话：
鉴于甲乙双方就共同开发园区项目达成一致意见，特订立本协议如下：
第一条 合作内容
甲乙双方将合作开发位于（园区位置）的园区项目，合作内容包括但不限于规划设计、建设施工、运营管理等各个阶段的工作。
第二条 合作方式
甲乙双方采取（合作方式）方式进行合作，共同承担风险和收益。
第三条 合作期限
本协议自签署之日起生效，至园区项目建成并运营达到双方约定的目标时为止。
第四条 费用分配
甲乙双方按照约定比例分配各项费用支出，具体分配比例为（比例详情）。
第五条 知识产权
园区项目中涉及的知识产权归甲乙双方共有，双方有义务保护和合理利用知识产权。
第六条 保密条款
甲乙双方在合作过程中涉及到的商业机密及合作协议内容均为保密信息，不得向第三方透露。
第七条 争议解决
本协议如有争议，应通过友好协商解决；协商不成的，提交（仲裁机构）仲裁解决。
甲方（盖章）： 乙方（盖章）：
签订日期： 签订日期：
英文：
Party A (Developer Company Name):
Address:
Telephone:

Party B (Cooperation Partner Name):
Address:
Telephone:
In consideration of the fact that Party A and Party B have reached an agreement on the joint development of the park project, this agreement is hereby entered into as follows:
Article 1 Cooperation Content
Party A and Party B will cooperate in the development of the park project located in (park location), including but not limited to planning and design, construction, operation management, and other stages of work.
Article 2 Cooperation Mode
Party A and Party B will cooperate in the manner of (cooperation mode), sharing risks and benefits.
Article 3 Cooperation Period
This agreement shall come into effect on the date of signature and shall remain in effect until the park project is completed and operated to the agreed target of both parties.
Article 4 Fee Allocation
Party A and Party B shall allocate various expenses according to the agreed ratio, with a specific distribution ratio of (ratio details).
Article 5 Intellectual Property Rights
The intellectual property rights involved in the park project belong to both Party A and Party B, and both parties are obligated to protect and reasonably utilize the intellectual property rights.
Article 6 Confidentiality
The business secrets and cooperation agreement contents involved in the cooperation between Party A and Party B shall be regarded as confidential information and shall not be disclosed to third parties.
Article 7 Dispute Resolution
In the event of a dispute arising from this agreement, the parties shall seek resolution through amicable negotiations; failing which, the dispute shall be referred to arbitration by (arbitration body) for resolution.
Party A (Seal): Party B (Seal):
Date: Date:
**2. 园区开发投资协议书**

中文：
甲方（投资方名称）：
地址：
电话：
乙方（开发公司名称）：
地址：
电话：
鉴于甲方有意向投资乙方位于（园区位置）的园区项目，特制定本协议如下：
第一条 投资内容
甲方将向乙方投资园区项目建设和运营中所需的资金，包括但不限于规划设计费、施工费、设备购置费等。
第二条 投资额及分期
甲方拟向乙方投资金额为（投资额），分期支付，具体分期付款计划如下：（分期详情）。
第三条 投资收益
园区项目运营后，甲方将获得相应的投资收益，包括但不限于分红、股权增值等形式。
第四条 项目利润分配
投资收益按照约定比例分配，具体分配比例为（比例详情）。
第五条 保密条款

甲乙双方在合作过程中产生的商业秘密和合作协议内容应保密，未经对方同意不得向第三方透露。
第六条 争议解决
本协议如有争议，应通过友好协商解决；协商不成的，提交（仲裁机构）仲裁解决。
甲方（盖章）： 乙方（盖章）：
签订日期： 签订日期：
英文：
Party A (Investor Name):
Address:
Telephone:
Party B (Developer Company Name):
Address:
Telephone:
Whereas Party A intends to invest in the park project of Party B located in (park location), this agreement is hereby formulated as follows:
Article 1 Investment Content
Party A will invest funds in the park project construction and operation of Party B, including but not limited to planning and design fees, construction costs, equipment purchase costs, etc.
Article 2 Investment Amount and Installments
Party A intends to invest an amount of (investment amount) in Party B, to be paid in installments. The specific installment payment plan is as follows: (installment details).
Article 3 Investment Returns
After the operation of the park project, Party A will receive corresponding investment returns, including but not limited to dividends, equity appreciation, etc.
Article 4 Project Profit Distribution
Investment returns shall be distributed according to the agreed ratio, with a specific distribution ratio of (ratio details).
Article 5 Confidentiality
The business secrets and cooperation agreement contents generated by Party A and Party B during the cooperation should be kept confidential and shall not be disclosed to third parties without the consent of the other party.
Article 6 Dispute Resolution
In the event of a dispute arising from this agreement, the parties shall seek resolution through amicable negotiations; failing which, the dispute shall be referred to arbitration by (arbitration body) for resolution.
Party A (Seal): Party B (Seal):
Date: Date:
**3. 园区开发合作协议书**
中文：
甲方（开发公司名称）：
地址：
电话：
乙方（合作方名称）：
地址：
电话：
鉴于甲方和乙方都有意向合作开发园区项目，特订立本协议如下：
第一条 合作内容
甲方和乙方将共同开发园区项目，包括但不限于规划设计、土地开发、建设施工、物业管理等工作。
第二条 合作方式
甲方和乙方将以共同投资的方式进行合作开发，共同承担风险和收益。
第三条 合作期限
本协议自签署之日起生效，至园区项目建成并运营达到双方约定的目标时为止。
第四条 利益分配
甲方和乙方按约定比例分配合作过程中的费用支出及利润，具体比例为（比例详情）。
第五条 保密条款
甲乙双方在合作过程中产生的商业秘密及合作协议内容应保密，未经对方同意不得向第三方透露。
第六条 争议解决
本协议如有争议，应通过友好协商解决；协商不成的，提交（仲裁机构）仲裁解决。
甲方（盖章）： 乙方（盖章）：
签订日期： 签订日期：
英文：
Party A (Developer Company Name):
Address:
Telephone:
Party B (Cooperation Partner Name):
Address:
Telephone:
Whereas Party A and Party B both intend to cooperate in the development of the park project, this agreement is hereby entered into as follows:
Article 1 Cooperation Content
Party A and Party B will jointly develop the park project, including but not limited to planning and design, land development, construction, property management, etc.
Article 2 Cooperation Mode
Party A and Party B will cooperate in the form of joint investment, sharing risks and benefits.
Article 3 Cooperation Period
This agreement shall come into effect on the date of signature and shall remain in effect until the park project is completed and operated to the agreed target of both parties.
Article 4 Benefit Distribution
Party A and Party B shall allocate expenses and profits incurred during the cooperation according to the agreed ratio, with a specific ratio of (ratio details).
Article 5 Confidentiality
The business secrets and cooperation agreement contents generated by Party A and Party B during the cooperation shall be kept confidential and shall not be disclosed to third parties without the consent of the other party.
Article 6 Dispute Resolution
In the event of a dispute arising from this agreement, the parties shall seek resolution through amicable negotiations; failing which, the dispute shall be referred to arbitration by (arbitration body) for resolution.
Party A (Seal): Party B (Seal):
Date: Date:
**4. 园区开发承建合同协议书**
中文：
甲方（开发公司名称）：
地址：
电话：
乙方（承建公司名称）：
地址：
电话：
鉴于甲方拟委托乙方承建园区项目，特订立本协议如下：
第一条 承建内容
乙方将根据甲方提供的项目规划设计图纸和要求，承担园区项目的建设施工任务。
第二条 工程报价
乙方应按照甲方提供的设计图纸和技术要求，合理报价园区项目的施工费用。
第三条 工期安排
双方应在合同中明确园区项目的开工日期、完工日期及各阶段验收时间，确保施工进度。
第四条 质量保证
乙方承建的园区项目应符合相关国家标准及甲方的技术要求，质量合格后方可交付使用。
第五条 维护保养
乙方应在竣工交付后保障园区项目的维护保养工作一段时间，并提供必要的技术支持。
第六条 争议解决
本协议如有争议，应通过友好协商解决；协商不成的，提交（仲裁机构）仲裁解决。
甲方（盖章）： 乙方（盖章）：
签订日期： 签订日期：
英文：
Party A (Developer Company Name):
Address:
Telephone:
Party B (Construction Company Name):
Address:
Telephone:
Whereas Party A intends to entrust Party B with the construction of the park project, this agreement is hereby entered into as follows:
Article 1 Construction Content
Party B shall undertake the construction tasks of the park project based on the project planning and design drawings and requirements provided by Party A.
Article 2 Engineering Quotation
Party B shall provide a reasonable quotation for the construction cost of the park project according to the design drawings and technical requirements provided by Party A.
Article 3 Construction Schedule
Both parties shall clearly define the commencement date, completion date, and various stage acceptance times of the park project in the contract to ensure construction progress.
Article 4 Quality Guarantee
The park project constructed by Party B shall meet relevant national standards and the technical requirements of Party A, and shall only be delivered for use after meeting the quality requirements.
Article 5 Maintenance
Party B shall guarantee the maintenance of the park project for a period of time after completion and delivery, and shall provide necessary technical support.
Article 6 Dispute Resolution
In the event of a dispute arising from this agreement, the parties shall seek resolution through amicable negotiations; failing which, the dispute shall be referred to arbitration by (arbitration body) for resolution.
Party A (Seal): Party B (Seal):
Date: Date:
**5. 园区开发出让合同协议书**
中文：
甲方（政府部门名称）：
地址：
电话：
乙方（开发公司名称）：
地址：
电话：
鉴于甲方拟将园区用地出让给乙方进行开发，特订立本协议如下：
第一条 出让内容
甲方将位于（园区位置）的园区用地出让给乙方进行开发建设，并明确出让面积、使用性质和出让条件。
第二条 出让价格及付款方式
出让价格为（出让价格），乙方应按照约定的付款方式及时间支付全款，并按规定办理相关手续。
第三条 使用权期限
乙方取得该园区用地的使用权期限为（使用权期限），届期可续期或转让。
第四条 开发要求
乙方应按照甲方的规划设计要求、施工标准及规定的时间要求开发园区用地，确保项目质量。
第五条 保密条款
甲乙双方在合作过程中产生的商业机密和合作协议内容应予保密，不得向第三方透露。
第六条 争议解决
本协议如有争议，应通过友好协商解决；协商不成的，提交（仲裁机构）仲裁解决。
甲方（盖章）： 乙方（盖章）：
签订日期： 签订日期：
英文：
Party A (Government Department Name):
Address:
Telephone:
Party B (Developer Company Name):
Address:
Telephone:
Whereas Party A intends to transfer the park land to Party B for development, this agreement is hereby entered into as follows:

Article 1 Transfer Content
Party A shall transfer the park land located in (park location) to Party B for development and construction, specifying the transfer area, land use nature, and transfer conditions.
Article 2 Transfer Price and Payment Method
The transfer price is (transfer price), and Party B shall pay